Terms & Conditions
Home / Terms & Conditions
- Subject to these Terms and Conditions, the Promotion commences at 10:00 am on the 1st of March 2024 and continues until 11:59 on the 24th of March 2024 or such time as the Promotion is otherwise terminated, cancelled, or suspended by Coral Homes in its absolute discretion (Promotion Period). The Promotion is not to be used in conjunction with any other Coral Homes offer unless otherwise approved in writing by an authorised representative of Coral Homes.
- Elegance Inclusions may vary depending on your choice of home design. All products and selection options will be nominated by Coral Homes. Due to the continuing development of our product, Coral Homes reserves the right to alter product specifications and suppliers at any time and without notice.
- Geographic restrictions may apply to the availability of some of the Elegance Inclusions. Not all upgrade items in the offer are available for all home designs.
- The promotion is only available:
- During the Promotion Period
- In respect of new preliminary agreements entered into:
- between Coral Homes and retail customers:
- in respect of those homes with the ‘Elegance specification; and
- based on Coral Homes’ Elegance price lists, effective from the 1st of March 2024;
- If no other promotion is entered into.
- For the purposes of these Terms and Conditions, unless the context clearly indicates otherwise:
- (a) “Elegance specification”, in respect of homes, means those homes which are the subject of Coral Homes’ “Elegance Inclusions”. A copy of the full Elegance Specification and Elegance brochure may be obtained at a Coral Homes display centre or may be viewed here
- (b) “Option”, means each of the inclusions and upgrades specified in paragraphs 8 to 14.
- (c) “Single Storey Homes”, in respect of a home, means those Coral Homes’ home designs constituting the following design ranges as specified in the Home Designs section of the Coral Homes website, which include:
(i) Single Storey Homes Narrow Lots;
(ii) Single Storey Homes Traditional Lots; and
(iii) Acreage Homes.
- (d) “Double Storey Homes”, in respect of a home, means those Coral Homes’ home designs constituting the “Double Storey Homes” range as specified in the Home Designs section of the Coral Homes website. Note that geographic restrictions apply to the availability of some double storey home designs.
- (e) “Service Region”, in respect of geography, means the region where Coral Homes builds homes constituting “Where we build” as specified on the Coral Homes website coralhomes.com.au/where-we-build.
- (f) “Standard Inclusions” of the offer means each of the inclusions specified within each region are inclusive of the Promotion;
- To the maximum extent permitted by law, Coral Homes reserves the right to vary, suspend, cancel or terminate the Promotion, the operation of the Promotion or these Terms and Conditions in its absolute discretion and without notice.
- Due to the continuing development of Coral Homes’ designs and products, to the maximum extent permitted by law, Coral Homes reserves the right to alter its product specifications and suppliers at any time and without notice.
- The Promotion shall be governed in accordance with the laws of the State or Territory in which your home is being constructed or is to be constructed. You submit to the non-exclusive jurisdiction of the courts of that State or Territory.
- The Promotion is only available in respect of Coral Homes’ homes with the applicable inclusions specifications. The Promotion is not available:
(i) for homes with Coral Homes’ Designer specifications; or
(ii) in conjunction with any other promotion, offer or inclusion specifications unless otherwise approved in writing by an authorised representative of Coral Homes’ Head Office: or
(iii) in certain geographic areas. Please speak with your Coral Homes Sales Consultant to ensure the availability of the Promotion/inclusion in respect of the location of your proposed home. In geographic areas outside of the Coral Homes Service Region, please speak with your Coral Homes New Home Consultant to ensure the availability of the Promotion and/or inclusions in respect of the location of your proposed home.
Options- There are six (6) Options or upgrades available in connection to the Promotion (Option). Availability of Options will depend upon whether the home is a Single Storey home or Double Storey home.
- The value of this Promotion will vary depending on your chosen home design and/or the geographic location in which the home will be constructed.
- Up to $50,000 is based on the retail cost of the ‘Elegance Inclusions’ upgrades on the Atlanta 474Q & 477N (“Q” & “N” are state specific where “Q” is for Queensland Regions and “N” is for new South Wales Regions) for the Brisbane, Gold Coast and Sunshine Coast price list regions as of 1st of March 2024. Value excludes Hervey Bay region. The average value of the inclusions in the Offer is $30,938 for a single storey home and $42,917 for a double storey home. The price shown is in addition to the Elegance Luxury Inclusions price of the chosen home design.
- In respect of Single Storey homes, Narrow Lots, Traditional, and Acreage lots, the ‘Elegance Inclusions’ promotion is included at no extra cost (being in addition to the price payable in respect of the relevant home).
- In respect of Double Storey homes, the ‘Elegance Inclusions’ promotion is included at no extra cost (being in addition to the price payable in respect of the relevant home).
- You will not be given a credit for the deletion of any Option. Each of the Options are not redeemable for cash and are not transferable. A credit is not provided for the staircase option when selecting a Single Storey home design.
- Descriptions and full details of the Options (as applicable) are set out in further detail below:
- (a) The air conditioner unit size will be determined by Coral Homes and varies depending on the choice of home design. The size of unit, zones and outlets are determined by Coral Homes and include an isolating switch. All Daikin air conditioning systems which may be included in this Promotion consist of 4 zones and include a standard inverter.
- (b) To the maximum extent permitted by law, Coral Homes gives no guarantee, warranty or representation in respect of any air conditioning provided in connection with this Promotion. You may have consumer guarantees under the Australian Consumer Law that may apply. Further, Daikin provides a 5-year warranty on the air conditioning unit and control. You should refer to the Daikin website for more information.
- (c) “Myair5 Air Management and an Android 8″ smart tablet is provided in lieu of the standard controller and zoning unit. MyAir5 is available with up to 10 zones and up to 10 temp sensors. Should you wish to add further zones or sensors than those stated above, please liaise with your Coral Homes New Home Consultant. Any additions to the zones or sensors may be at an additional cost.
- (d) The Promotion ducted air conditioning Inclusions option is based on a 6m setback and underground power being available to the site. If the system requires an upgrade to three (3) phase power this is included in the Promotion. Further details and specifications of ducted air conditioning available for these Inclusions, please liaise with your Coral Homes New Home Consultant.
- (a) MyPlace Modules which includes 1x relay module and 6x switch points. Should you wish to add further relays or switch points than those stated above, please liaise with your Coral Homes New Home Consultant or MyChoice Consultant. Any additions to the relays or switch points may be at an additional cost.
- (b) MyPlace can control most 240-volt hard-wired devices in the home, making them smart.
- (c) MyPlace can control but is not limited to:
- Garage Doors; 3rd Party Lights (downlights, Pendants, garden, LED, pool, wall, security); MyPlace App for remote access; MyApps – integration with other Apps like: ARLO | ARLO LEGACY | RING| FRONIUS | SOLAR EDGE |SPOTIFY | SONOS.
- Carpet Option
For this Option, the carpet to areas of the home will be as nominated on Coral Homes’ standard floor covering layouts. You may ask a Coral Homes New Home Consultant for the floor covering layout of your chosen home design. If you choose this Inclusion:
- (a) the carpet must be selected from Carpet Call’s “Rumble” range;
- (b) you may choose from six colours;
- (c) the carpet includes 7mm foam underlay; and
- (d) you must nominate the carpet colour at the time of your colour appointment.
- Tiling Option
For this Option, the floor tiling to main floors (which you may select from the Builder’s specified range) will be as nominated on Coral Homes’ standard floor covering layouts. You may ask a Coral Homes New Home Consultant for the floor covering layout of your chosen home design. If you choose this Inclusion:
- (a) tiling will be plain straight laying pattern only;
- (b) the floor tiles available for the Tiling Inclusion may be selected from the Builder’s standard range of up to 600mm x 600mm pressed-edge glazed ceramic tiles;
- (c) includes ‘Score and Snap’ tiles only.
You must nominate the carpet colour at the time of your colour appointment; and you may be charged additional costs for:
-
- (i) larger tiles/tile variations outside of Coral Homes nominated tiles;
- (ii) laying costs per square metre for any rectified edge floor tiles (porcelain / vitrified etc.). This will be charged by Coral Homes to the Owner by way of Variation to Contract.
- (iii) alignment of floor tiling grout lines to other areas. Should you wish for floor tiling grout to align further charges apply; and any floor tiles you select that require diamond blade cutting.
-
- COVER – Carpet Cover Grade
- BALUSTRADE – Glass to rakes
- OTHER – Timber stained first tread, raiser and handrail
-
- (a) Up to thirty (30) downlights to the entry, hallway, pantry, dining & kitchen.
- (b) You must nominate the placement of these downlights at the time of your electrical and lighting appointment with Clipspec.
- (c) All products and selection options will be nominated by Coral Homes. Due to the continuing development of our product, Coral Homes reserves the right to alter product specifications and suppliers at any time and without notice.
- (d) All other ‘Elegance Inclusions’ terms and conditions listed above are applicable during this promotion.
- The Promotion is available on all house and land, fixed site costs and standard order projects for new customers and new home preliminary agreements only entered from 10:00 am Friday 1st of March 2024.
- A Price Lock or additional Price Lock months cannot be added after the new home preliminary agreement has been entered into.
- Tender or contract must be ordered within 28 days of deposit.
- The Promotion is not available to existing customers. Existing customers cannot move to the 1st of March 2024 price list and take advantage of any of the Promotion Options.
- To ensure the Promotion can be received, all contracts must be signed within 14 calendar days of issue by Coral Homes, and a 5% deposit fully paid at the time of contract signing (after contract has been issued by Coral Homes).
- Customers will have 180 days from the initial deposit to the site start request date plus any applicable price lock days from the date of the signed preliminary agreement to complete all tasks to satisfy the terms of the contract to enable site start to be issued. All contract terms must be met prior to the issue of a site start date.
- Coral Homes will not be held responsible for any time delays due to pending National Construction Code (NCC) changes including but not limited to ‘Energy Efficiency’ and ‘Accessible Housing’. Coral Homes reserves the right to suspend the operation of the Price Hold Promotion in its absolute discretion and without notice should changes to the NCC take effect.
- If there is any inconsistency between these terms and conditions and any other published information in relation to the Promotion, these terms and conditions will prevail to the extent of the inconsistency.
- This Promotion and the provision of any benefit under this Promotion is not transferable.
- You will not be given a credit for the deletion of any Standard Inclusion. Each of the Options and Standard Inclusions are not redeemable for cash and are not transferrable.
- Coral Homes may collect personal information about you for the purposes of the Promotion which will be maintained in accordance with applicable laws.
- The terms of the Privacy Policies applicable to Coral Homes apply to this Promotion.
- Coral Homes and each of its related bodies corporate, directors, officers, employees, contractors and/or consultants disclaim all liability for any loss or damage which is suffered or sustained by you or any third party arising out of or in connection with the Promotion except to the extent such loss or damage has been caused by the unlawful or negligent act or omission of any of them.
- If any part of these terms and conditions are determined to be invalid, unlawful or unenforceable for any reason then that part, to the extent of the invalidity, unlawfulness or unenforceability, will be severed from the rest of the terms and conditions and the remaining terms and conditions will continue to be valid and enforceable to the fullest extent permitted by law.
- Please speak with your Coral Homes sales consultant to ensure the availability of the Promotion and/or permitted changes in respect of the location of your proposed home.
- Without limiting any other provision of these Terms and Conditions, Coral Homes reserves the right to vary, terminate or suspend the operation of the Promotion in its absolute discretion at any time before you enter into an agreement for Coral Homes’ and without notice to you.
- National Construction Code (NCC) Changes For all details relating to the National Construction Code (NCC 2022), please refer to the terms and conditions available here for QLD and here for NSW.
- Subject to these Terms and Conditions, the Promotion commences at 10:00 am on the 1st of March 2024 and continues until 11:59 pm on the 24th of March 2024 or such time as the Promotion is otherwise terminated, cancelled, or suspended by Coral Homes in its absolute discretion (Promotion Period). The Promotion is not to be used in conjunction with any other Coral Homes offer unless otherwise approved in writing by an authorised representative of Coral Homes.
- The Promotion is broken into region-specific offers and is only available in the following price list regions:
- (a) Brisbane, Sunshine Coast, Gold Coast (Region 1) which the customer may select from one of the following options:
- Option 1: Up to $30,000 price reduction on double storey homes and up to $20,000, price reduction on single storey homes,
- Option 2: Premium Upgrades
- (b) Newcastle (Central Coast) & Sydney (Region 2) which the customer may select from one of the following options:
- Option 1: Up to a $30,000 price reduction on double storey homes and up to a $20,000 price reduction on single storey homes,
- Option 2: Premium Upgrades
- (c) Tweed, Ballina, Lismore, Byron, Coffs Harbour, Hervey Bay and Port Macquarie (Region 3) which the customer may select from one of the following options:
- Option 1: Up to a $30,000 price reduction on double storey homes and up to a $20,000 price reduction on single storey homes,
- Option 2: Premium Upgrades
- The promotion is only available:
-
- (i) During the Promotion Period
- (ii) In respect of new preliminary agreements entered into:
-
-
- between Coral Homes and retail customers:
- In respect of those homes with the ‘Designer’ specification; and
- based on Coral Homes’ Designer price lists, effective from 1st of March 2024;
-
-
- (iii) If no other promotion is entered into.
- For the purpose of these Terms and Conditions, unless the context clearly indicates otherwise:
- (a) “Bathroom” or “Bathrooms”, in respect of a home, means bathrooms, powder rooms and WC’s except for the Ensuite as defined in paragraph 4(c), as shown in Coral Homes’ standard plans and specified in the Home Designs section of the Coral Homes website.
- (b) “Designer specification”, in respect of homes, means those homes which are the subject of Coral Homes’ “Designer inclusions”. A copy of the full Designer specification may be obtained at a Coral Homes display centre or may be viewed here for QLD or here for NSW.
- (c) “Double Storey Homes”, in respect of a home, means those Coral Homes’ home designs constituting the “Double Storey Homes” range as specified in the Home Designs section of the Coral Homes website. Note that geographic restrictions apply to the availability of some double storey home designs.
- (d) “Ensuite”, in respect of a home, means the bathroom adjoining the master bedroom as shown in Coral Homes’ standard plans, as specified in the Home Designs section of the Coral Homes website.
- (e) “Option” has the meaning given in paragraph 9.
- (f) “Option 1 – Price Reduction”, “Option 2 – Premium Upgrades” mean those Options specified in paragraphs 10, 11 and 12.
- (g) “Standard Inclusions” of the offer means each of the inclusions specified within each region are inclusive of the Promotion;
- (h) “Single Storey Homes”, in respect of a home, means those Coral Homes’ home designs constituting the following design ranges as specified in the Home Designs section of the Coral Homes website, which include:
-
- Single Storey Homes Narrow Lot;
- Single Storey Homes Traditional Lot: and
- Acreage Homes.
-
- (i) “Double Storey Homes”, in respect of a home, means those Coral Homes’ home designs constituting the “Double Storey Homes” range as specified in the Home Designs section of the Coral Homes website. Note that geographic restrictions apply to the availability of some double storey home designs.
- (j) “Service Region”, in respect of geography, means the region where Coral Homes builds homes constituting “Where we build” as specified on the Coral Homes website coralhomes.com.au/where-we-build.
- To the maximum extent permitted by law, if terms stipulated by Coral Homes are not met by the customer, Coral Homes reserves the right to vary, suspend, cancel or terminate the Promotion, the operation of the Promotion or these Terms and Conditions in its absolute discretion and without notice.
- Due to the continuing development of Coral Homes’ designs and products, to the maximum extent permitted by law, Coral Homes reserves the right to alter its product specifications and suppliers at any time and without notice.
- The Promotion shall be governed in accordance with the laws of the State or Territory in which your home is being constructed or is to be constructed. You agree to submit to the non-exclusive jurisdiction of the courts of that State or Territory.
- The Promotion is only available in respect of certain Coral Homes’ homes with the applicable inclusions’ specification and in certain geographic areas. The Promotion is not available:
-
- (i) For homes with Coral Homes’ Elegance inclusions specification: or
- (ii) In conjunction with any other promotion, offer or inclusion specifications unless otherwise approved in writing by an authorised representative of Coral Homes’ Head Office: or
- (iii) In certain geographic areas. Please speak with your Coral Homes Sales Consultant to ensure availability of the Promotion/inclusion in respect of the location of your proposed home.
-
- There are two (2) options available in connection to the Promotion (Options). Availability of options will depend upon whether the home is a Single Storey “Narrow Lot”, “Traditional Lot”, “Acreage” or “Double Storey” Home. The offer is available to specific regions and pricing is dependent by region (including, as detailed above) and home design type. Each of the Options cannot be used in conjunction with any other Option and the available Options are as follows:
- Option 1 – Price Reduction
- (a) Brisbane, Gold Coast & Sunshine Coast build regions
- In respect to all “Double Storey” homes: take off up to $30,000* on the original base price of double storey homes.
- In respect to all “Single Storey” homes: take off up to $20,000* on the original base price of single storey homes; inclusive of Narrow Lot, Traditional Lot and Acreage Lot homes.
- Option 1 ‘Price reduction’ offer – Double storey price reduction shown is based on the Atlanta 474Q home design with Designer façade. Price reductions are based on homes with Designer Inclusions in the Brisbane, Gold Coast and Sunshine Coast price list area in which the average price reduction in these areas for a double storey home is $30,000. Single storey price reduction shown is based on a Highlands 338Q home design with Designer facade. Price reductions are based on homes with Designer Inclusions in the Brisbane, Gold Coast and Sunshine Coast price area in which the average price reduction in these areas for a single storey home is $20,000.
- Designer Solutions – Price Reduction offer (Option 1) cannot be used in conjunction with any other options from this Promotion including “Option 2 – Premium Upgrades” of this Promotion.
- (b) Newcastle/Central Coast & Sydney build regions
- In respect to all “Double Storey” homes: take off up to $30,000* on the original base price of double storey homes.
- In respect to all “Single Storey” homes: take off up to $20,000* on the original base price of single storey homes; inclusive of Narrow Lot, Traditional Lot and Acreage Lot homes.
- Option 1 ‘Price reduction’ offer – Double storey price reduction shown is based on the Atlanta 477N home design with Designer façade. Price reductions are based on homes with Designer Inclusions in the Newcastle/Central Coast & Sydney price list area in which the average price reduction in these areas for a double storey home is $30,000. Single storey price reduction shown is based on a Highlands 340N home design with Designer facade. Price reductions are based on homes with Designer Inclusions in the Newcastle/Central Coast & Sydney price list area in which the average price reduction in these areas for a single storey home is $20,000.
- Designer Solutions – Price Reduction offer – (Option 1) cannot be used in conjunction with any other options from this Promotion including “Option 2 – Premium Upgrades” of this Promotion.
- (c) Tweed, Ballina, Lismore, Byron, Coffs Harbour, Hervey Bay and Port Macquarie build regions
- In respect to all “Double Storey” homes: Take off up to $30,000* on the original base price of double storey homes.
- In respect to all “Single Storey” homes: take off up to $20,000* on the original base price of single storey homes; inclusive of Narrow Lot, Traditional Lot and Acreage Lot homes.
- Option 1 ‘Price reduction’ offer – Double storey price reduction shown is based on the Atlanta 474Q & Atlanta 477N (state specific where “Q” is for Queensland Regions and “N” is for new South Wales Regions) home design with Designer façade. Price reductions are based on homes with Designer Inclusions in the Tweed, Ballina, Lismore, Byron, Coffs Harbour, Hervey Bay and Port Macquarie price list areas in which the average price reduction in these areas for a double storey home is $30,000. Single storey price reduction shown is based on a Highlands 338Q & Highlands 340N (state specific where “Q” is for Queensland Regions and “N” is for new South Wales Regions) home design with Designer facade. Price reductions are based on homes with Designer inclusions in the Tweed, Ballina, Lismore, Byron, Coffs Harbour, Hervey Bay and Port Macquarie price list areas in which the average price reduction in these areas for a single storey home is $20,000.
- Designer Solutions – Price Reduction offer – (Option 1) cannot be used in conjunction with any other options from this Promotion including “Option 2 – Premium Upgrades” of this Promotion.
- Option 2 – Premium Upgrades
- (a) Prices shown are only applicable for new home preliminary agreements entered into from 10:00 am, Friday 1st of March 2024.
Lot | Port Macquarie | Tweed | Ballina | Brisbane | Sydney | Newcastle/ Central Coast | Hervey Bay | Coffs Harbour |
Narrow | $2999 | $2999 | $2999 | $2999 | $2999 | $2999 | $2999 | $2999 |
Acreage | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 |
Traditional | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 |
Double storey | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 | $5999 |
- (b) Due to the continuing development of Coral Homes’ designs and products, Coral Homes reserves the right to alter its product specifications and suppliers at any time and without notice.
- (c) Price is dependent on both home design and build region.
- (d) Designer Solutions– Premium Upgrades (Option 2) cannot be used in conjunction with any other offer/promotion by Coral Homes, or by any of the options from this Promotion including “Option 1 – Price Reduction”.
- (e) In respect to all home designs, “Option 2 – Premium Upgrades” is Inclusive of:
- Option A:
- Option B:
-
- (i) Technika FHEE229SC9S-5 900mm stainless steel wall mounted canopy rangehood with four speeds, LED lamps and sensor touch control; or
- (ii) Technika CHEM52C9S-5 900mm stainless steel wall mounted canopy rangehood, with three speed push button electric control, two halogen globes and ducted through ceiling; or
- (iii) Technika GEH9017 900mm front re-circulating slide out rangehood with three speeds.
-
- High ceiling areas to be nominated by Coral Homes.
- Face brickwork will be provided above front elevation window openings and front entry door where required. Excludes infill panel above garage door which will have painted fibre cement panels above. Note: Standard ceiling height is 2400mm high
-
- Choose from builders’ standard range at the time of your colour appointment.
- You may choose from [6] six colours.
- Colour availability is subject to change without notice.
- The carpet includes 7mm foam underlay.
-
- Floor tiles are 450×450 ceramic tiles from builders’ standard range to main floor areas only (as nominated by Coral Homes)
- This excludes types including but not limited to rectified edge, ceramic, vitrified and have maximum dimensions of 450mm x 450mm.
- Based on plain straight laying pattern only (with builders’ standard grout colours).
- Main floor tiling is not included under stairs (Design Specific).
- Price excludes alignment of floor tiling grout lines to other areas.
- To take advantage of the Promotion, you must choose (and you are only entitled to choose) one only of the above Options available to you (including in respect of your region). You cannot choose more than one of the above Options as part of the Promotion. If you choose more than one of the above Options, Coral Homes may in its absolute discretion cancel or suspend your right to participate in the Promotion.
- Further descriptions and full details of these Options, including the relevant Inclusions (as applicable) are set out in further detail below.
- To take advantage of the Promotion, if you are a client of Coral Homes building a “Single Storey Home” or “Double Storey Home” with Designer specification, you:
- must enter into a preliminary agreement with Coral Homes during the Promotion Period;
- must promptly enter into a construction contract for a Coral Homes Home with Designer inclusions;
- must, and will be taken to, accept these terms and conditions.
- The Promotion is available on all house and land, fixed site costs and standard order projects for new customers and new home preliminary agreements only entered from 10:00 am Friday 1st of March 2024.
- A Price Lock or additional Price Lock months cannot be added after the new home preliminary agreement has been entered into.
- Tender or contract must be ordered within 28 days of deposit.
- The Promotion is not available to existing customers. Existing customers cannot move to the 1st of March 2024 price list and take advantage of any of the Promotion Options.
- To ensure the Promotion can be received, all contracts must be signed within 14 calendar days of issue by Coral Homes, and a 5% deposit fully paid at time of contract signing (after contract has been issued by Coral Homes).
- Customers will have 180 days from initial deposit to the site start request date plus any applicable price lock days from the date of the signed preliminary agreement to complete all tasks to satisfy the terms of the contract to enable site start to be issued. All contract terms must be met prior to the issue of a site start date.
- Coral Homes will not be held responsible for any time delays due to pending National Construction Code (NCC) changes including but not limited to ‘Energy Efficiency’ and ‘Accessible Housing’. Coral Homes reserves the right to suspend the operation of the Price Hold Promotion in its absolute discretion and without notice should changes to the NCC take effect.
- If there is any inconsistency between these terms and conditions and any other published information in relation to the Promotion, these terms and conditions will prevail to the extent of the inconsistency.
- This Promotion and the provision of any benefit under this Promotion is not transferable.
- You will not be given a credit for the deletion of any Standard Inclusion. Each of the Options and Standard Inclusions are not redeemable for cash and are not transferrable.
- Coral Homes may collect personal information about you for the purposes of the Promotion which will be maintained in accordance with applicable laws.
- The terms of the Privacy Policies applicable to Coral Homes apply to this Promotion.
- Coral Homes and each of its related bodies corporate, directors, officers, employees, contractors and/or consultants disclaim all liability for any loss or damage which is suffered or sustained by you or any third party arising out of or in connection with the Promotion except to the extent such loss or damage has been caused by the unlawful or negligent act or omission of any of them.
- If any part of these terms and conditions are determined to be invalid, unlawful or unenforceable for any reason then that part, to the extent of the invalidity, unlawfulness or unenforceability, will be severed from the rest of the terms and conditions and the remaining terms and conditions will continue to be valid and enforceable to the fullest extent permitted by law.
- Please speak with your Coral Homes sales consultant to ensure the availability of the Promotion and/or permitted changes in respect of the location of your proposed home.
- Without limiting any other provision of these Terms and Conditions, Coral Homes reserves the right to vary, terminate or suspend the operation of the Promotion in its absolute discretion at any time before you enter into an agreement for Coral Homes’ and without notice to you.
- National Construction Code (NCC) Changes For all details relating to the National Construction Code (NCC 2022), please refer to the terms and conditions available here for QLD and here for NSW
TERMS AND CONDITIONS – Price Lock until 2025
*The ‘Price Lock until 2025’ offer applies to Preliminary Agreements prepared by Coral Homes based on the 1st of March 2024 pricelist or later and is available for all home designs, specification levels, to Brisbane, Gold Coast and Sunshine Coast price list regions only (as specified by Coral Homes) and continues until 11:59pm March 24th, 2024, unless otherwise stated, at such time as the Promotion is terminated, cancelled, or suspended by Coral Homes in its absolute discretion. (Promotion Period). Single Storey for only $3,999 refers to the price to pay for price lock for Narrow lot, Traditional and Acreage home designs (region-specific). Double Storey included for a limited time only refers to the price to pay ($0) for price lock for Double Storey home designs (region-specific).
The ‘Price Lock until 2025’ offer is strictly limited to anyone who has paid an initial deposit on or after the 1st of March 2024 price list. The Anticipated Site Start date (QLD) of the contract will be the 3rd of January 2025 plus an additional 28 calendar days as per the HIA Building contract: Totalling a price lock to 31st of January 2025.
Without limiting any other provision of these Terms and Conditions, Coral Homes reserves the right to vary, terminate or suspend the operation of the Promotion in its absolute discretion at any time before you enter into an agreement for Coral Homes’ and without notice.
This offer is subject to the following qualifications, terms, and conditions:- (i) Contract must be issued by Coral Homes head office on or before the 31st of August 2024.
- (ii) Contract to be signed within 14 calendar days of issue and a balance of 5% deposit paid within 7 calendar days of the contract signing.
- (iii) The Price Lock periods and amounts are not available to existing customers.
- (iv) The project must still achieve the anticipated start date/essentials matters date regardless of the price lock offer.
- (v) The ‘Price Lock’ promotion (offer) is strictly limited to new customers who pay an initial deposit from 1st of March 2024 on the Designer & Elegance pricelists.
- (vi) If the above terms stipulated by Coral Homes are not met, Coral Homes reserves the right to review the tender letter, price list and promotional offer (specific to each individual customer) to determine the outcome of the file.
- (vii) Price Lock cannot be used in conjunction with any other price lock offer (under the table or otherwise).
- (viii) Price Lock offer is available to Designer & Elegance specification/inclusions levels.
- (ix) Coral Homes reserves the right to withdraw, vary or terminate the offer at its absolute discretion and without notice.
^’Lowest Price Guarantee’ offer – transfer to lower base house price is only available to those who qualify for the January 2025 price lock and until the date in which the building contract is signed. If the lower base house price is requested, this must be taken with the inclusions and promotional offers available with the new price list.
#‘Price reduction’ offer – Up to $30,000 price reduction on double storey homes is based on the Atlanta 474Q home design with Designer facade and up to $20,000, price reduction is based on the Highlands 338Q home design with Designer facade. Price reductions are based on homes with Designer inclusions in the Brisbane, Gold Coast, Sunshine Coast, Sydney, Newcastle, and Central Coast regions (including Hervey Bay, Tweed, Ballina, Coffs Harbour and Port Macquarie regions) in which the average price reduction in these areas is listed within the terms and conditions of Coral Homes’ website. Price reduction offer is not available to Elegance specification. No allowance has been made for Energy Efficiency changes due to come into effect from 1 May 2024. All costs to comply with these requirements will incur an additional cost to the customer including but not limited to window and door glazing upgrades change of roof/wall/window colours or upgraded insulation.
For further information, please speak with a Coral Homes New Home Consultant.
Changes to the National Construction Code
For all details relating to the National Construction Code (NCC 2022), please refer to the terms and conditions available here for QLD.
TERMS AND CONDITIONS – Price Lock until 2025
- Price Lock until 2025 – Newcastle, Central Coast and Sydney price list regions only.
- *The ‘Price Lock until 2025’ offer applies to Preliminary Agreements prepared by Coral Homes based on the 1st of March 2024 pricelist or later and is available for all home designs, specification levels, to Newcastle, Central Coast and Sydney price list regions only (as specified by Coral Homes) and continues until 11:59pm 24th of March, 2024, unless otherwise stated, at such time as the Promotion is terminated, cancelled, or suspended by Coral Homes in its absolute discretion. (Promotion Period). Single Storey included for a limited time only refers to the price to pay ($0) for price lock for Narrow lot, Traditional and Acreage home designs (region-specific). Double Storey included for a limited time only refers to the price to pay ($0) for price lock for Double Storey home designs (region-specific).
- Price Lock until 2025 – Ballina, Coffs Harbour and Tweed price list regions only.
- *The ‘Price Lock until 2025’ offer applies to Preliminary Agreements prepared by Coral Homes based on the 1st of March 2024 pricelist or later and is available for all home designs, specification levels, to Ballina, Coffs Harbour and Tweed price list regions only (as specified by Coral Homes) and continues until 11:59pm 24th of March, 2024, unless otherwise stated, at such time as the Promotion is terminated, cancelled, or suspended by Coral Homes in its absolute discretion. (Promotion Period). Single Storey for only $3,999 refers to the price to pay for price lock for Narrow lot, Traditional and Acreage home designs (region-specific). Double Storey for only $6,999 refers to the price to pay for price lock for Double Storey home designs (region-specific).
- The ‘Price Lock until 2025’ offer is strictly limited to anyone who has paid an initial deposit on or after the 1st of March 2024 price list. Essential matters date (NSW) of the contract will be the 3rd of January 2025, plus an additional 28 calendar days as per the HIA Building contract: Totalling a price lock to the 31st January 2025.
- Without limiting any other provision of these Terms and Conditions, Coral Homes reserves the right to vary, terminate or suspend the operation of the Promotion in its absolute discretion at any time before you enter into an agreement for Coral Homes’ and without notice.
- This offer is subject to the following qualifications, terms, and conditions:
- Contract must be issued by Coral Homes head office on or before the 31st of August 2024.
- Contract to be signed within 14 calendar days of issue and a balance of 5% deposit paid within 7 calendar days of the contract signing.
- The offer is available for the regions specified only, and for the price-to-pay amounts for each specified region as listed above.
- The Price Lock periods and amounts are not available to existing customers.
- The project must still achieve the anticipated start date/essentials matters date regardless of the price lock offer.
- The ‘Price Lock’ promotion (offer) is strictly limited to new customers who pay an initial deposit from the 1st of March 2024 on the Designer & Elegance pricelists.
- If the above terms stipulated by Coral Homes are not met, Coral Homes reserves the right to review the tender letter, price list and promotional offer (specific to each individual customer) to determine the outcome of the file.
- Price Lock cannot be used in conjunction with any other price lock offer (under the table or otherwise).
- Price Lock offer is available to Designer & Elegance specification/inclusions levels.
- Coral Homes reserves the right to withdraw, vary or terminate the offer at its absolute discretion and without notice.
- ^’Lowest Price Guarantee’ offer – transfer to lower base house price is only available to those who qualify for the January 2025 price lock and until the date in which the building contract is signed. If the lower base house price is requested, this must be taken with the inclusions and promotional offers available with the new price list.
- #‘Price reduction’ offer – Up to $30,000 price reduction on double storey homes is based on the Atlanta 477N home design with Designer facade and up to $20,000, price reduction is based on the Highlands 340N home design with Designer facade. Price reductions are based on homes with Designer inclusions in the Brisbane, Gold Coast, Sunshine Coast, Sydney, Newcastle, and Central Coast regions (including Hervey Bay, Tweed, Ballina, Coffs Harbour and Port Macquarie regions) in which the average price reduction in these areas is listed within the terms and conditions of Coral Homes’ website. Price reduction offer is not available to Elegance specification. While some allowance has been made for the NCC requirements relating to ‘Energy Efficiency’ in the base house price, any additional costs will apply for Building Sustainability Index (BASIX) compliance for items including but not limited to window and door glazing upgrades, change of roof/wall/window colours or upgraded insulation. All costs to comply with these requirements will incur an additional cost to the customer.
For further information, please speak with a Coral Homes New Home Consultant.
Changes to the National Construction Code
For all details relating to the National Construction Code (NCC 2022), please refer to the terms and conditions available here for NSW.
- Promotion Period and Availability
- 1.1. Subject to these terms and conditions, the Promotion is effective for deposits received after 10:00 am on the 1st of March 2024 for customers selecting either Designer Solutions or Elegance Inclusions and continues until such time until the Promotion is terminated, cancelled, or suspended by Coral Homes.
- 1.2. The Promotion is only available to customers who select a Traditional or Narrow lot home design and is strictly limited to 50 customers across QLD and NSW. The Promotion is only available during the Promotion Period in respect of new preliminary agreements entered into with Coral Homes during the time the promotion is offered.
- 1.3. Coral Homes reserves the right to substitute the steel house frame with termite treated timber to its absolute discretion where supply and installation is delayed. For homes located within proximity of surf or exposed marine influences (to where a steel frame is not eligible for a 50-year warranty from Bluescope steel) termite treated timber will be utilised. Steel Frame and Colorbond roof offer is subject to change without notice.
- 1.4. The promotion is available in the following Coral Homes’ price list regions:
Ballina, Lismore & Byron $999 | Brisbane, Sunshine Coast, Gold Coast $999 | Coffs Harbour $2999 | Hervey Bay $1999 |
Newcastle $0 | Port Macquarie $0 | Sydney $0 | Tweed $999 |
Ballina, Lismore & Byron $999 | Brisbane, Sunshine Coast, Gold Coast $999 | Coffs Harbour $2999 | Hervey Bay $1999 |
Newcastle $0 | Port Macquarie $0 | Sydney $0 | Tweed $999 |
-
- 1.5. The Promotion is not available:
-
-
- in conjunction with any other promotion, offer or inclusions specification unless otherwise stated in writing by Coral Homes’ Head Office;
- for wind ratings N4/C1 or greater;
- for homes located within 300m of surf or exposed marine influences where the steel used in the house frame is not eligible for a warranty from the steel manufacturer;
- for duplex or similar attached dwellings.
-
- Conditions of Promotion
- 2.1. Coral Homes reserves the right to vary, terminate, extend or suspend the operation of the Promotion in its absolute discretion and without notice.
- 2.2. Due to the continuing development of Coral Homes’ designs and products, Coral Homes reserves the right to alter its product specifications and suppliers at any time and without notice.
- 2.3. Due to salt water influence, further costs which are not included in this promotion may be applicable. Coral Homes’ Head Office will obtain confirmation from the manufacturer and reserve the right to cancel this offer due to salt water influence.
- 2.4. Due to building in bushfire prone area requirements, further costs which are not included in this promotion may be applicable.
- 2.5. Please Note: Some non-structural framing elements including but not limited to framing battens to cladded walls and soffit framing battens will remain timber.
- Promotional Offer
- 3.1. To take advantage of the Promotion, if you are a client of Coral Homes and building in the Promotion Regions, you must:
-
-
- enter into a preliminary agreement with Coral Homes during the Promotion Period;
- enter into a construction contract;
- and will be taken to accept these terms and conditions.
-
- Details of Promotion
-
- 4.1. Steel Roof
- The Promotion includes a roof made from sheet roofing, with turbine roof ventilator/s (design specific) and Anticon insulation blanket (region specific).
- Colour of roof to be selected from the Builder’s standard range at time of colour appointment (additional costs will apply should the owner nominate to use colours outside of the Builder’s standard range such as matt colours from the manufacturer or sheet roofing to suit coastal or industrial environments). Note: the steel roof will be installed to conform to AS 1562.1 – 1992 Design and installation of sheet roof and wall cladding – Metal.
- 4.2. Steel House Frame
- The house frame will include frames and roof trusses made from steel.
- Framing made from steel to remain at 600mm stud spacings and roof truss spacings to be 1200mm.
- Minor ceiling height differences may occur dependent upon steel frame manufacturer.
- Coral Homes reserves the right to use between a 70mm – 90mm frame in lieu of the standard 70mm or 90mm frame if needed. Framing is to remain 70mm or 90mm unless stated otherwise. If an alternate frame size is required, the external footprint of the building is to remain as shown on plans and internal room dimensions will be reduced to suit.
- 4.3. Non-redeemable
- You will not be given a credit for the deletion of any item in this Promotion. Each of the items are not redeemable for cash and are not transferrable.
- This promotion is administered by Coral Homes and not the manufacturer. To the maximum extent permitted by law, the manufacturer is not responsible or liable for the administration of this promotion and you should direct any questions regarding this offer to Coral Homes.
- 4.1. Steel Roof
The Fixed Price Guarantee applies to Contracts entered into by Coral Homes Pty Ltd (ACN 011 032 929), Coral Homes Qld Pty Ltd (ACN 097 304 062), QBCC 50792 / 1014053 and NSW OFT 62084C, BLD 260339 (Coral Homes, our, us), subject to the terms and conditions set out in this document (Terms and Conditions).
Our Fixed Price Guarantee is intended to help you build a new home by providing certainty. Before commencing construction, Coral Homes will specify in your Contract a fixed price for the building and site works specified in the Contract. This provides you with the knowledge that there are no hidden extra costs.
Prior to construction, we will agree with you a fixed price in respect of the costs of construction of your house and associated site works in accordance with the specifications of your Contract.
Fixed Price Guarantee Terms and Conditions- For the purposes of these Terms and Conditions:
- (a) Site Works means costs of the minimum site works for compliance with building and statutory requirements which are associated with labour, material, plant hire, sewerage connection, rock excavation, stormwater connection, water connection and additional engineering requirements (apart from extra costs associated with raising building platforms/floor levels).
- (b) Mandatory Items include but is not limited to the following in respect of the site, the registered plan, contour survey, soil test, supervisor site inspection including public risk assessment, natural gas form, location of water service connection point, recycled water availability including location of connection point, telecommunication service information including location of connection point, sewer information including “as constructed” stormwater plans clearly indicating all dimensions of mains from boundaries and surface levels/invert levels of both the mains and the house connections points, stormwater information including “as constructed” stormwater plans clearly indicating all dimensions of mains from boundaries and surface levels/invert levels of both the mains and the house connection points, preliminary town planning assessment and covenant requirements and any other information as we may reasonably require.
- (c) Contract refers to your New Home Construction Contract, New Home Tender and any Post Contract Variations signed prior to the commencement of the construction of your house.
- Subject to clause 3 of these Terms and Conditions, Coral Homes represents and warrants that the costs of construction of the house and Site Works in accordance with the specification set out in the Contract will be for a fixed amount as specified in the Contract (Fixed Price Guarantee).
- The Fixed Price Guarantee does not apply to preliminary contracts entered into before you provide the Mandatory Items to us.
- You must promptly provide to us all required information and Mandatory Items in order for Coral Homes to provide you with a Fixed Price Guarantee.
- These Terms and Conditions shall be governed in accordance with the law of the State in which your home is being constructed or is to be constructed. You submit to the non-exclusive jurisdiction of the courts in that State.
- To the extent of any inconsistencies between these Terms and Conditions and your Contract, the Contract shall prevail.
- You are not entitled to rely on the words or conduct of Coral Homes as a waiver of any right pursuant to these Terms and Conditions unless that waiver is in writing and signed by an authorised representative of Coral Homes.
- Coral Homes reserves the right to vary, terminate or suspend the operation of the Fixed Price Guarantee offer in its absolute discretion, without notice, at any time provided that such variation, termination or suspension shall have no affect on existing building contracts at such time.
Acreage Living Advertising September 2023
Terms and Conditions of the pricing for the display fence banner artwork and digital advertising (region specific). Facade shown is based on the Highlands 338Q & 340N with the Display Lodge Facade. This facade is not included in the advertised price and depicts non-standard items including (but not limited to) the following: feature stone, brick and timber, render finish, 2340mm entry door height, stained entry door frame, window treatment, and feature lighting. Additional facade upgrades may be at an additional cost or not available.
*Based on Home Design Highlands 255Q and 256N with Designer Facade. Pricing shown per the below table is region specific, based on Coral Homes build regions and is specific to the March 1st 2024 price list.
Hervey Bay | $353,900 ($365,700 – $11,800 – option 1 Designer Solutions offer) |
Brisbane/Gold Coast/ Sunshine Coast | $286,100 ($297,000 – $10,900 – option 1 Designer Solutions offer) |
Tweed | $303,500 ($315,200 – $11,700 – option 1 Designer Solutions offer) |
Ballina/Lismore/Byron | $344,100 ($357,000 – $12,900 – option 1 Designer Solutions offer) |
Coffs Harbour | $356,900 ($370,100 – $13,200 – option 1 Designer Solutions offer) |
Port Macquarie | $396,500 ($412,700 – $16,200 – option 1 Designer Solutions offer) |
Newcastle/Central Coast | $326,900 ($341,500 – $14,600 – option 1 Designer Solutions offer) |
Sydney | $340,300 ($353,700 – $13,400 – option 1 Designer Solutions offer) |
Pricing includes Coral Homes “Designer Solutions” Option 1 – Price reduction which has been applied.
Coral Homes reserves the right to vary, terminate, alter or withdraw the pricing, plans and inclusions at their absolute discretion and without notice. All costs to comply with changes to the National Construction Code (NCC 2022) requirements will be at the cost to the owner. Landscaping and fencing is not supplied by Coral Homes. Please speak with a Coral Homes New Home Consultant for more details. QBCC 50792 / 1014053 & NSW OFT 62084C.
Highlands 255Q Hamptons or Lodge Façade Offer Digital Advertising March 2024
The Highlands 255Q Hamptons or Lodge Façade could be yours from $279,590* with Coral Homes.
*Based on Highlands 255Q with either Hamptons or Lodge Façade in the Brisbane, Gold Coast, Sunshine Coast Price List Region and the March 1st, 2024 Price List. Designer Standard Inclusions selected with Hamptons or Lodge façade, Steel frame and Colorbond roof with Option One Designer Solutions Price Reduction selected and the $30,000 First Home Owners Grant included. ($297,000 + $23,790 – $11,200 – $30,000 = $279,590).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
Evoke 169Q Advertised Price March 2024
The Evoke 169Q could be yours from $207,790* with Coral Homes.
*Based on Home Design Evoke 169Q with Shoreline Facade in the Brisbane, Gold Coast, Sunshine Coast Price List Region and the March 1st, 2024 Price List ($241,300) Designer Standard Inclusions selected with Shoreline façade and Colorbond roof ($4,290) Option One Designer Solutions Price Reduction selected (-$7,800) and the $30,000 First Home Owners Grant included. ($241,300 + $4,290 – $7,800 – $30,000 = $207,790).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
Monash 236Q Advertised Price March 2024
The Monash 236Q could be yours from $347,990* with Coral Homes.
*Based on Home Design Monash 236Q with Hamptons Facade in the Brisbane, Gold Coast, Sunshine Coast Price List Region and the March 1st, 2024 Price List ($366,400) Designer Standard Inclusions selected with Hamptons façade and Colorbond roof ($21,690) Option One Designer Solutions Price Reduction selected (-$10,100) and the $30,000 First Home Owners Grant included. ($366,400 + $21,690– $10,100 – $30,000 = $347,990).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
Atlanta 402N Advertised Price March 2024
The Atlanta 402N could be yours from $549,990* with Coral Homes.
*Based on Home Design Atlanta 402N with Modern Facade in the Newcastle and Central Coast Price List Region and the March 1st, 2024 Price List ($539,700) Designer Standard Inclusions selected with Modern façade ($31,290) Option One Designer Solutions Price Reduction selected (-$21,000). ($539,700 + $31,290 – $21,000 = $549,990).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
Monash 262N Advertised Price March 2024
The Monash 262N could be yours from $419,290* with Coral Homes.
*Based on Home Design Monash 262N with Hamptons Facade in the Newcastle and Central Coast Price List Region and the March 1st, 2024 Price List ($420,500) Designer Standard Inclusions selected with Hamptons façade ($22,790) Option One Designer Solutions Price Reduction selected (-$14,000) and the $10,000 First Home Owners Grant included. ($420,500 + $22,790 – $14,000 – $10,000 = $419,290).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
Lisbon 253Q Advertised Price March 2024
The Lisbon 253Q could be yours from $277,190* with Coral Homes.
*Based on Home Design Lisbon 253Q with Hamptons Facade in the Brisbane, Gold Coast and Sunshine Coast Price List Region and the March 1st, 2024 Price List ($299,100) Designer Standard Inclusions selected with Modern façade ($18,590) Option One Designer Solutions Price Reduction selected (-$10,500) and the $30,000 First Home Owners Grant included. ($299,100+ $18,590– $10,500 -$30,000= $277,190).
Land not included. The price shown does not include additional amounts payable in respect of variations to the house design requested by the buyer, upgraded facades or any other incidental fees associated with the acquisition of the home. Pricing is to be used as a guide only and may vary. Coral Homes reserves the right to withdraw and change pricing without notice. Facade images are indicative only and may depict landscaping, timber decking, furniture, window treatments, driveway, fencing, lighting, non-standard roof covering and other features which may not be included in the facade price or which may not be available from Coral Homes.
For further details please speak with a Coral Homes New Home Consultant. QBCC 50792 / 1014053 & NSW OFT 62084C.
The “Fixed Price Home and Land with Zero to Pay Up Front” promotion (Promotion) is being conducted by Coral Homes Pty Ltd ACN 011 032 929 and Coral Homes Qld Pty Ltd ACN 097 304 062, QBCC 50792 / 1014053 and NSW OFT 62084C (Coral Homes) subject to the terms and conditions set out in this document.
Subject to these terms and conditions, the Promotion commences at 10:00am on Saturday, 4th July 2015 (Promotion Period).
1. For the purposes of these Terms and Conditions unless the context clearly indicates otherwise:
a. “Change” means any variation, change, modification or additional item in respect of the structure, external modifications, roof, insulation, internal area, wet area, kitchen, appliances, finishes or external works of the home which are made available from Coral Homes from time to time.
b. “Standard Design” means the standard design for a home as published by Coral Homes from time to time.
2. Where the home is:
a. a single storey home, there must be no more than:
i. 18 Changes to the Standard Design for the home (including those specified in the price of the home and land package)
b. a two storey home, there must be no more than:
i. 18 Changes to the Standard Design for the home (including those specified in the price of the home and land package)
3. For the purposes of clause 2, any Changes to the home which arise from any promotions of Coral Homes made available from time to time in respect of the home or home design shall not be included in the calculation of the number of Changes.
4. Subject to clauses 2 and 3, the only permitted Changes to the home or home design of a structural nature will be in respect of:
a. changes to the pitch of the roof for the home;
b. adding or deleting eaves for the home;
c. building the home to boundary walls for the block on which the home is built;
d. having higher ceilings than the standard for the home;
e. allowing for under eave bulkheads for the home where it is a one storey home only;
f. addition of a façade option to the home;
g. use of a steel frame for the home;
h. using integrated slabs in respect of the home; or
i. any current display home option without further reconfiguration.
Otherwise, no structural Changes to the home shall be permitted.
5. Other than in connection with those Changes contemplated by clause 4 and subject at all times to clause 6, there must be:
a. no Changes to the building footprint for the home; and
b. no reconfiguring of the standard plan for the home.
6. The Changes contemplated by clause 4 will not be permitted by way of a variation to your building contract with Coral Homes after such building contract has been signed by all parties.
7. You must promptly provide to us all required information and mandatory items in order for Coral Homes to prepare your quotation; this includes:
a. Disclosure documentation
b. Plan of Development or building envelope
c. Acoustic reports
d. Bushfire reports
e. Covenants
8. Modified Standard Plans (MSP) and Owner Supplied Plans (OSP) are excluded from the Promotion.
9. Subject to these Terms and Conditions being met, Coral Homes will provide a fixed price quotation for your home and land package
10. Acceptance of the quotation will be in the form of a signed Preliminary Agreement at which time you will be required to pay an initial deposit so that Coral Homes can conduct testing on your block. Please refer to your Sales Consultant regarding the amount required for the initial deposit in your region, and for further conditions surrounding your Preliminary Agreement. The initial deposit is nonrefundable, but is deducted from the contract price by way of a reduction to the 5% deposit on your new home should you enter into a building agreement with Coral Homes for the building works.
11. The balance of your 5% deposit is payable on signing a contract with Coral Homes.
12. Coral Homes reserves the right to refuse the Promotion if any of the above conditions are not met, or if site conditions or Local Authority requirements dictate further changes are necessary beyond those noted above.
13. Coral Homes reserves the right to vary, terminate or suspend the operation of the Promotion in its absolute discretion at any time and without notice to you prior to you entering into a contract with Coral Homes
14. The Promotion may not be available in certain geographic areas. Please speak with your Coral Homes sales consultant to ensure availability of the Promotion in respect of the location of your proposed home.
15. These Terms and Conditions shall be governed in accordance with the law of the State in which your home is being constructed or is to be constructed. You submit to the non-exclusive jurisdiction of the courts in that State.
16. These Terms and Conditions constitute the entire agreement between Coral Homes and you in respect of the Promotion. Any change or variation to these Terms and Conditions must be in writing.
17. You must not assign or otherwise deal with these Terms and Conditions or any rights or obligations under these Terms and Conditions, without the prior written consent of Coral Homes.
18. You are not entitled to rely on the words or conduct of Coral Homes as a waiver of any right pursuant to these Terms and Conditions unless that waiver is in writing and signed by an authorised representative of Coral Homes.
19. All notices given in connection with these Terms and Conditions may be given by personal delivery, certified mail, e-mail, facsimile or any other customary means of communication
20. If any provision of these Terms and Conditions is invalid under the law of any jurisdiction, the provision is enforceable in that jurisdiction to the extent that it is not invalid, whether it is in severable terms or not. This clause does not apply where enforcement of the provision of these Terms and Conditions in accordance with this clause would materially affect the nature or effect of the parties’ obligations under these Terms and Conditions.
21. In these Terms and Conditions a reference to a clause is a reference to a clause of these Terms and Conditions
22. Due to the continuing development of Coral Homes’ designs and products, Coral Homes reserves the right to alter its product specifications and suppliers at any time and without notice.
Energy efficiency inclusions have been based on modelling completed on single and double storey homes located in various locations and orientations. No allowance has been made for site-specific window and door glazing upgrades. The Energy Efficiency inclusions are intended to be a baseline level only and will require additional changes to suit location, framing type, roof/wall materials, roof/wall/window/door colours, and orientation of the home.
Coral Homes recommend using light colours to roof/wall/window/doors with solar absorptance ratings of 0.40 or less in the Tweed, Ballina / Lismore / Byron, Coffs Harbour, Pricelist area/s . The use of medium or dark colours with absorptance ratings of 0.40 or more will likely require higher costs for additional items to achieve whole of house and 7-star energy rating compliance when compared to light colours in the Tweed, Ballina / Lismore / Byron, Coffs Harbour, Pricelist area/s. Once the official energy assessment has been completed any further requirements will be charged to the customer by way of Variation.
Changes to the National Construction Code
The National Construction Code of Australia (NCC) is a performance-based code that sets the minimum requirements in relation to structure, fire safety, accessibility, health and amenity, and sustainability. #NCC Qualification: Changes to the National Construction Code (NCC 2022) requirements relating to ‘Accessible Housing’ are effective from 1 October 2023. The NCC 2022 requirements (including but not limited to) the new ‘Accessible Housing’ requirements have been applied to Coral Homes inclusions and floorplans. The National Construction Code (NCC) is due to introduce updates to the ‘Energy Efficiency’ requirements for release 1 May 2024. NCC requirements relating to ‘Energy Efficiency’ have not been applied and additional costs may apply for items including (but not limited to) window and door glazing upgrades (Base prices include clear float to habitable rooms and obscure glass to wet areas). Subject to developer covenant requirements, Coral Homes recommend using light colours to roof/wall/window/doors with solar absorptance ratings of 0.40 or less. The NCC 2022 is subject to ongoing review and may be updated or changed in the future. Accordingly, the inclusions, floorplans, and homes on display (and featured within this guide) are subject to change without notice in order to comply with the requirements of the NCC 2022 including but not limited to ‘Energy Efficiency’ & ‘Accessible Housing’. Coral Homes reserves the right to vary, terminate, alter, or withdraw the plans, inclusions and offer at their absolute discretion and without notice. Coral Homes will not be responsible for any additional costs associated with changes to the floorplans or inclusions to ensure they comply with the NCC 2022. Such costs may be passed on to, and will be required to be paid by the customer. For further details please speak with a Coral Homes New Home Consultant.Changes to the National Construction Code
The National Construction Code of Australia (NCC) is a performance-based code that sets the minimum requirements in relation to structure, fire safety, accessibility, health and amenity, and sustainability.
#NCC Qualification: Changes to the National Construction Code (NCC 2022) requirements relating to ‘Accessible Housing’ are effective from 1 October 2023. The NCC 2022 requirements (including but not limited to) the new ‘Accessible Housing’ requirements have been applied to Coral Homes inclusions and floorplans. While some allowance has been made for the NCC requirements relating to ‘Energy Efficiency’ in the base house price, any additional costs will apply for Building Sustainability Index (BASIX) compliance for items including but not limited to window and door glazing upgrades, change of roof/wall/window colours or upgraded insulation. (Base prices include single glazed clear float to habitable rooms and obscure glass to wet areas).
The NCC 2022 is subject to ongoing review and may be updated or changed in the future. Accordingly, the inclusions, floorplans, offers and homes on display are subject to change without notice in order to comply with the requirements of the NCC 2022 including but not limited to ‘Energy Efficiency’ & ‘Accessible Housing’.
Coral Homes reserves the right to vary, terminate, alter, or withdraw the plans and inclusions at their absolute discretion and without notice. Coral Homes will not be responsible for any additional costs associated with changes to the floorplans or inclusions to ensure they comply with the NCC 2022. Such costs may be passed on to and will be required to be paid by the customer.
For further details please speak with a Coral Homes New Home Consultant.